Cases Decided in the Court of Claims of the United States, Volumes 160-171 |
From inside the book
Results 1-3 of 83
Page 385
... delivery or perform- ance dates . In the event that Government - Furnished property is not delivered to the Contractor by such time or times , the Contracting Officer shall , if requested by the Contractor , make a determination of the ...
... delivery or perform- ance dates . In the event that Government - Furnished property is not delivered to the Contractor by such time or times , the Contracting Officer shall , if requested by the Contractor , make a determination of the ...
Page 439
... delivery schedule on subject Supply Contract ; One effect of this time extension was to relieve plaintiff of liability for non - delivery of 275 rifles by the end of June 1953 as per requirements of the original contract . ( d ) On ...
... delivery schedule on subject Supply Contract ; One effect of this time extension was to relieve plaintiff of liability for non - delivery of 275 rifles by the end of June 1953 as per requirements of the original contract . ( d ) On ...
Page 440
... delivery schedule requirements to 100 rifles per month at no increased cost to the Government . Said POD : " This should be a delivery schedule which you can make and if you do make it the penalty clause will not take effect . As you ...
... delivery schedule requirements to 100 rifles per month at no increased cost to the Government . Said POD : " This should be a delivery schedule which you can make and if you do make it the penalty clause will not take effect . As you ...
Other editions - View all
Common terms and phrases
Acme Acme's action adjustment administrative agreement Air Force amount appeal Army basis Board breach cancellation Capehart Housing captains change order Clinton County cofferdam Company concrete contingent fees contract price contracting officer Corp costs Court 171 Ct damages decision deductions defendant defendant's delay delivery depletion determination employee entitled to recover equipment evidence expenditures expenses Fact 171 Ct February 19 filed Findings of Fact Government grade incurred issued June June 11 Kennecott Kentucky National Guard Lansdale latex letter liquidated damages machine Manalapan manganese March ment Metals mining Norris October October 23 operation Opinion of Commissioner paid parties patent payment percent performance piles plaintiff prime contractor prior production reasonable record requested rifles schedule settlement sewer specifications subcontractor substitute facilities Supp supra surface texture termination claim tiff tion Tract Tucker United USSRMCO Utah Copper wage Watervliet Arsenal