...language in Clause 5 of the General Provisions (Standard Form 23-A) is clear that the Government : * * * shall ascertain the facts and the extent of the delay and extend the time for completing the work * * *. This Board has held that the duty is upon the contracting officer to obtain the weather data...

...causes of delay. The clause expressly empowers the contracting officer to extend the completion date when in his judgment the findings of fact justify such an extension and provides that the findings of fact arc final and conclusive subject only to the contractor's right...

...the contract) notify the contracting officer in writing of the causes of delay, who shall ascertion the facts and the extent of the delay and extend the...fact justify such an extension, and his findings of fact thereon shall be final and conclusive on the parties hereto, subject only to appeal, within thirty...

...«.»•' - In writing of the causes of delay, t'pon receipt of such notice, the Contract:: officer shall ascertain the facts and the extent of the delay and extend the :. • for completing the work specified in Article I -I! or otherwise excuse the ii. •. when In...

...delay. The Contracting Officer shall ascertain the fans and the extent of the dela> and extend (he time for completing the work when in his judgment the findings of fait justify such an extension, and his findings uf fac( shall be hnal and conclusive on the parties...

...the contract) notify the contracting officer in writing of the causes of delay, who shall ascertion the facts and the extent of the delay and extend the...fact justify such an extension, and his findings of fact thereon shall be final and conclusive on the parties hereto, subject only to appeal, within thirty...

...the contract) notify the contract* ing officer in writing of the causes of delay, who shall ascertion the facts and the extent of the delay and extend the...fact justify such an extension, and his findings of fact thereon shall be final and conclusive on the parties hereto, subject only to appeal, within thirty...

...severe weather. The Contractor promptly shall notify the Owner of such delay. The Owner shall thereupon ascertain the facts and the extent of the delay and extend the time for completion when he determines that the Contractor is entitled to such extension under the terms of...

...severe weather. The Contractor promptly shall notify the Owner of such delay. The Owner shall thereupon ascertain the facts and the extent of the delay and extend the time for completion when he determines that the Contractor is entitled to such extension under the term* of...

...severe weather. The Contractor promptly shall notify the Owner of such delay. The Owner shall thereupon ascertain the facts and the extent of the delay and extend the time for completion when ho determines that the Contractor is entitled to such extension under the terms of...